Terms and Conditions
Email:
 info@eastwestdevelopments.com
Phone: +44 8701826515
Fax: +44 8445852550
www.eastwestdevelopments.com
TERMS & CONDITIONS.
This entire page, including the DISCLAIMERS and the PRIVACY POLICY are part of the TERMS AND CONDITIONS. Eastwest Developments is also referred as Developer or Company or Seller. The Buyer is also referred as Purchaser, Customer or Partner.

The Buyer acknowledges and agrees that: 

The Buyer has read, understood, agree and accept all the Terms & Conditions, including Disclaimers on the projected earning potential. 
THE BUYERS ARE REQUESTED TO DO THEIR OWN DUE DILIGENCE, AND CONSULT THEIR OWN TAX AND FINANCIAL ADVISORS BEFORE MAKING A PURCHASE.
The Developer reserves the right to accept or reject any purchase application received. 

At each location all maps, dimensions, drawings, architectural plans, building material and appearance, location, site area, lot size, dimensions, shape and plan, construction start date,  construction period, completion dates, site & floor plans etc are approximate and information is subject to change without  notice.  The Seller reserves the right to make revisions. The website will be updated at regular intervals. Buyer when making a purchase, agrees to accept these revisions.
 

The Sellers website: www.eastwestdevelopments.com is a very important document. It will always have the latest, and most updated information on current properties and their completion  dates.  Both the Seller and the Partners/owners/buyers agree to abide and be legally bound by the details printed and published on the website.
Whatever is mentioned on this website. The buyer gets that. The Seller and Company representatives cannot give information or make commitment to the Buyers other than what is published on the website.
 
Regarding Payment to the Partners/owners/buyers:  ~ All payments to the Partners/owners/buyers will be given after one month of the completion date of their purchased property. The valid completion date for payment will be one month after the date on the official Occupation Certificate as issued by the Building Department of the City. 
~ All payments when made will be released to all the Partners/owners/buyers at the same time. Advance payments, Loans or part payments to any one individual Partner/owner/buyer before the completion date will not be released.
Nor will the Seller issue or give Letters of Credit,  statements, Account records, supporting letters or copies of official company records or documents of any kind  to the  readers, public or partners/owners/buyers.

Regarding Payments, Cancellations and Refunds: ~ Buyer can cancel his purchase within 7 days and get a Full refund of the payment sent.  NO cancellations. NO refunds after 7 days, from the purchase date. All Bank & transaction charges are borne by the Buyer, unless where mentioned otherwise. East West Developments is providing property informations on an as is" basis and makes no warranties of earning or warranties of any kind.

The Buyer will be subject to and comply with all the requirements of the Property location Land Registration Rules.

All disputes arising in relation to any purchase shall be restricted and subject to the jurisdiction of the courts in the city  and in the country of the property location only.

East West Developments may modify these Terms of Use, or the website at any time, simply by updating these posting and without notice to the Buyers.

  DISCLAIMER ::

The Seller does not Purport the Buyer purchase as a "QUICK GET RICH SCHEME" Although this is clearly a preferential buying opportunity, the Buyer should be aware that no investment or return on investment is ever guaranteed. No representation is being made that your investment or return on investment will be the same as or resemble the examples given on our site. In fact, no representation is made that there will necessarily be any return on your investment. The examples are just one of many possible investment outcomes and are for purposes of illustration only. The Buyer investment, in this case, is in a project to be constructed.  Although the expectation is that this project will be built as planned, we make no representations or promises that the project will proceed as planned. Delays could happen. In case of delays, Developer will issue no refund, but the Developer will pay the delay penalty to the Buyers as mentioned on the property page. Buyer understands he cannot claim delays as an excuse for cancellation and refund of his payment. Only in the event the Developer cancels the project, then all funds will be returned in full, without interest.



The information herein is merely illustrative and promotional in nature, and does not represent a  guarantee or specific warranty regarding any particular Property info. No representation is made as to the success of any project, the ability of a purchaser to find a buyer, or that the prices within a particular project will rise. Real estate buyers should understand that if held for investment purposes, there is a risk that returns from other investment vehicles — such as a stock, bonds, interest or other property — could be higher. Accordingly, there is no guarantee that a pre-construction purchases represents the best possible investment relative to other possible uses of a buyer's money. Buyers should do their own due diligence and consult their own investment and tax advisors about the suitability of a pre-construction purchase for their particular needs and situations. The purchase of a pre-construction is a purchase of real estate for personal use. Accordingly, it is not intended to constitute a security.

The information provided here are calculations only. The rates, revenues and returns are expected estimates only based upon the analysis of market conditions and hotel & hospital management activity in the Local areas.

East West Developments makes no recommendations whatsoever with regard to the decision of any prospective buyer to purchase a property by the developer, other than to recommend to any prospective buyer that he/she should consult with his/her independent investment advisor, tax consultant and legal counsel.

East West Developments disclaim any responsibility for the project or performance and makes no representation or warranty, express or implied, as to the percentage of return of investment to any purchase of property..  

 DISCLAIMER ON PROJECTED EARNINGS:
EVERY EFFORT HAS BEEN MADE TO ACCURATELY REPRESENT THIS INFORMATION AND IT'S POTENTIAL. THERE IS NO GUARANTEE THAT THE BUYER WILL EARN ANY MONEY USING THE INFORMATION. EXAMPLES IN THESE MATERIALS ARE NOT TO BE INTERPRETED AS A PROMISE OR GUARANTEE OF EARNINGS. EARNING POTENTIAL IS ENTIRELY DEPENDENT ON THE PERSON.   
ANY AND ALL FORWARD LOOKING STATEMENTS ON OUR  WEBSITES, OR ON ANY OF OUR SALES MATERIAL ARE INTENDED TO EXPRESS OUR OPINION OF EARNINGS POTENTIAL. MANY FACTORS WILL BE IMPORTANT IN DETERMINING YOUR ACTUAL RESULTS AND NO GUARANTEES ARE MADE THAT YOU WILL ACHIEVE RESULTS SIMILAR TO OURS OR ANYBODY ELSE'S, IN FACT NO GUARANTEES ARE MADE THAT YOU WILL ACHIEVE ANY RESULTS FROM OUR IDEAS AND PRODUCTS. 
Pursuant to International, State & Federal Laws the following is a statement of your legal rights:
Disclaimer & Legal Rights  
EastWestDevelopments.com is providing this site and its contents on an "as is" basis and makes no representations or warranties of any kind with respect to this site(s) or its contents.  
No Warranties  
ALL WEB SITES. PRODUCTS AND SERVICES ARE PROVIDED, AS IS, WITHOUT WARRANTY OF ANY KIND, EITHER EXPRESS OR IMPLIED, INCLUDING, BUT NOT LIMITED TO, THE IMPLIED WARRANTIES OF MERCHANTABILITY, RESALE AND FITNESS FOR A PARTICULAR PURPOSE. OUR COMPANY DOES NOT WARRANT, GUARANTEE, OR MAKE ANY REPRESENTATIONS REGARDING THE USE, OR THE RESULTS OF THE USE, OF THE WEB SITES, PRODUCTS, SERVICES OR WRITTEN MATERIALS IN THE TERMS OF CORRECTNESS, ACCURACY, RELIABILITY, CURRENTNESS OR OTHERWISE THE ENTIRE RISK AS TO THE RESULTS AND PERFORMANCE OF THE WEB SITES, PRODUCTS AND SERVICES ARE ASSUMED BY THE BUYER. IF THE WEB SITES, PRODUCTS, SERVICES OR WRITTEN MATERIALS ARE DEFECTIVE, THE BUYER, AND NOT THE SELLER, ASSUME THE ENTIRE COST OF ALL NECESSARY SERVICING, REPAIR, RESALE OR CORRECTION.  
Customer Remedy 
The Sellers entire liability, and the Buyer's exclusive remedy, shall be part refund of the price paid or replacement of our products, at Seller's option.   
Limitation & Exclusion of Liability  
These warranties exclude all incidental or consequential damages. The Seller, and its suppliers, will not be liable for any damages whatsoever, including without limitations, damages for loss of business profits, business interruption, loss of business information, or other pecuniary loss. Some Countries do not allow the exclusion or limitation of liability, so the above limitations may not apply in those countries.  
Legal Forum, Choice of Law & Official Language 
This offering is a contract between you the buyer and our business, the seller. The seller is located in the location of the Property. And by doing business with us you agree that this offering is made from the location, and shall be governed by the laws of the Country/City where the property is located. 
Any dispute or disagreement between the Seller and the Buyer on any provision shall be mutually resolved. Inability to mutually resolve the dispute by the Seller and the Buyer, the dispute may be by mutual consent of the Parties be referred to a mutually agreed arbitrator. Such arbitration proceedings shall be undertaken in the City where the property is located. The dispute shall be subject to the laws of the Country where the property is located.
This agreement shall be governed by and construed in accordance with the laws of the Country/City where the property is located, without regard to its conflict of laws rules. Any legal action arising out of this Agreement shall be litigated and enforced under the laws of the Country/City where the property is located. In addition, the Seller and the Buyer agree to submit to the jurisdiction of the courts of the Country/City where the property is located, and that any legal action pursued shall be within the exclusive jurisdiction of the courts of the Country/City where the property is located.  
This agreement is being written in English, which is to be the official language of the contract text and interpretation. If you do not agree with the above terms and conditions, you have the option to not participate in this offer.  
Securities and Exchange Commission, USA:
East West Developments is not registered with the Securities and Exchange Commission, or licensed by the National Association of Securities Dealers of USA.  East West Development is an International Partner of organizations in locations not in USA, and their International Developments are not in USA. East West Development properties are not offered, advertised or available in USA. Properties are for personal use of the Buyers and are not Securities.
THE PROPERTY DETAILS ARE FOR ADVANCE INFORMATION PURPOSES ONLY. AND IS NOT AN OFFER OR A SOLICITATION FOR SALE. THIS INFORMATION IS NOT VALID, AND IS NOT MEANT FOR COUNTRIES WHERE GIVING SUCH INFORMATION IS PROHIBITED BY LAW. SALES WILL BE DONE LATER ONLY THRU A SEPARATE PROSPECTUS OF SALE.
 
 
 TERMS AND CONDITIONS OF USE
We have taken every effort to design our Web site to be useful, informative, helpful, honest and fun. Hopefully we've accomplished that - and would ask that you let us know if you'd like to see improvements or changes that would make it even easier for you to find the information you need and want.  
All we ask is that you agree to abide by the these Terms and Conditions. Please carefully read and understand them. If you don't agree, please do not use the site, and do not make purchases. We reserve the right to make any modifications that we deem necessary at any time. Please continue to check these terms to see what those changes may be! Your decision to purchase a unit and continued use of the EastWestDevelopments.com Web site means that you accept those changes.  
Due Diligence
The interested readers understand that the Property info published on the website, also contains the information gained by The Company under its due diligence program of property vetting. The information contained in the Property info website, to the best of The Company's knowledge, correct and true and shall contain no statement which The Company knowingly knows to be false, misleading, or otherwise incorrect. However, the information contained within the Property website may have been compiled, in full or in part, as a result of enquiries made within the Property location.  As this information often has to be gleaned from Third Parties, The Company cannot accept any liability for any false, inaccurate, or otherwise incorrect information contained within the Property website , where such information has had to be gleaned from such Third Parties.

Late Payment
The Company reserves the right to apply late payment penalties. All payments shall be first applied to interest and the balance to principal. In the event of payment default, the entire unpaid balance shall, at the option of the
Lender, become immediately due and payable. The Borrower will remain fully bound until full payment is made. In the event of default, the Borrower agrees to pay all reasonable solicitors fees and costs of collection.

Refund of Fees.
On purchase of a property, then there shall be no refund of fees owed if the purchaser is unable to proceed with the purchase of the property for any reasons.  It is the responsibility of the Purchaser to ensure that they are financially in a position to proceed with the purchase of a property through to completion before  reservation of that property.

Change of Property.

On rare occasions, due to circumstances beyond our control, it may no longer be possible to continue to purchase a property reserved through the Seller. On such occasions, The Company reserves the right to substitute the original property offered for sale and subsequently reserved to an alternative property. If this occurs, then the substitute property offered shall offer the same or better in terms of engagement, in thee opinion of the company, than that which was originally offered for sale to the client. The purchaser agrees to be guided by thee expert opinion of the company in this regard and shall accept and continue to purchase any substitute property offered to the purchaser in this regard, or can ask for a full refund. In such a case the full amount will be refunded without interest.
Real Estate Advertising Rules 
To best meet the needs of our users while accommodating the wide variety of laws governing the advertisement and promotion of real estate across the globe, www.eastwestdevelopments.com  offers advertisements of real estate in a variety of formats. These Real Estate Rules explain these format offerings, clarify www.EastWestDevelopments.com's limited role as a publisher of advertising and venue-provider, and outline certain limitations on www.EastWestDevelopments.com's obligations and liabilities. Your use of the www.EastWestDevelopments.com website confirms your agreement to these rules.  
Advertisement Format Items  
Due to the wide variety of laws governing the sale of real estate, www.EastWestDevelopments.com's advertisements of real property do not involve a legally binding offers to buy and sell. Instead, the www.EastWestDevelopments.com listings are simply a way for sellers, Realtors, and builders (herein referred to as "sellers") to advertise their pre-construction real estate and meet potential buyers. Keep in mind that www.EastWestDevelopments.com has no control over the quality, safety or legality of the properties advertised, the truth or accuracy of the postings, the ability of sellers to sell items or the ability of buyers to buy items. We cannot ensure that a buyer or seller will actually complete a transaction.  
Professional Assistance  
Prospective buyers are advised to perform all due diligence before purchasing or selling property. You are strongly advised to seek the help of a licensed real estate professional and/or a real estate attorney to help you in the purchase and sale of any real estate.
Limitation of Liability 
EastWestDevelopments.com WILL NOT BE LIABLE FOR ANY DAMAGES OR INJURY THAT ACCOMPANY OR RESULT FROM YOUR USE OF ANY OF ITS WEB SITE. 
THESE INCLUDE (BUT ARE NOT LIMITED TO) DAMAGES OR INJURY CAUSED BY ANY:  
  • USE OF (OR INABILITY TO USE) THE SITE
  • USE OF (OR INABILITY TO USE) ANY SITE TO WHICH YOU HYPERLINK FROM OUR SITE
  • FAILURE OF OUR SITE TO PERFORM IN THE MANNER YOU EXPECTED OR DESIRED
  • ERROR ON OUR SITE
  • OMISSION ON OUR SITE
  • INTERRUPTION OF AVAILABILITY OF OUR SITE
  • DEFECT ON OUR SITE 
  • DELAY IN OPERATION OR TRANSMISSION OF OUR SITE
  • COMPUTER VIRUS OR LINE FAILURE
  • PLEASE NOTE THAT WE ARE NOT LIABLE FOR ANY DAMAGES, INCLUDING:
    • DAMAGES INTENDED TO COMPENSATE SOMEONE DIRECTLY FOR A LOSS OR INJURY
    • DAMAGES REASONABLY EXPECTED TO RESULT FROM A LOSS OR INJURY (KNOWN IN LEGAL TERMS AS "CONSEQUENTIAL DAMAGES.")
    • OTHER MISCELLANEOUS DAMAGES AND EXPENSES RESULTING DIRECTLY FROM A LOSS OR INJURY (KNOWN IN LEGAL TERMS AS "INCIDENTAL DAMAGES.")
WE ARE NOT LIABLE EVEN IF WE'VE BEEN NEGLIGENT OR IF OUR AUTHORIZED REPRESENTATIVE HAS BEEN ADVISED OF THE POSSIBILITY OF SUCH DAMAGES OR BOTH.  
HOWEVER, IN ANY EVENT, OUR LIABILITY TO YOU FOR ALL LOSSES, DAMAGES, INJURIES, AND CLAIMS OF ANY AND EVERY KIND (WHETHER THE DAMAGES ARE CLAIMED UNDER THE TERMS OF A CONTRACT, OR CLAIMED TO BE CAUSED BY NEGLIGENCE OR OTHER WRONGFUL CONDUCT, OR THEY'RE CLAIMED UNDER ANY OTHER LEGAL THEORY) WILL NOT BE GREATER THAN THE AMOUNT YOU PAID.  
Links to Other Site 
We sometimes provide referrals to and links to other World Wide Web (WWW) sites from our site. Such a link should not be seen as an endorsement, approval or agreement with any information or resources offered at sites you can access through our site. If in doubt, always check the Uniform Resource Locator (URL) address provided in your WWW (or Internet) browser to see if you are still in a EastWestDevelopments.com -operated site or have moved to another site. EastWestDevelopments.com is not responsible for the content or practices of third party sites that may be linked to our site. When EastWestDevelopments.com provides links or references to other Web sites, no inference or assumption should be made and no representation should be inferred that EastWestDevelopments.com is connected with, operates or controls these Web sites. Any approved link must not represent in any way, either explicitly or by implication, that you have received the endorsement, sponsorship or support of any EastWestDevelopments.com site or endorsement, sponsorship or support of EastWestDevelopments.com , including its respective employees, agents or directors.  
  ADDITIONAL DISCLAIMER

East West Developments takes all reasonable care to ensure that the information on this website is accurate. However, we cannot guarantee its accuracy and we reserve the right to change the information on this website (including these terms and conditions) at any time. You must therefore check these terms and conditions for any such changes each time you visit this website. 

East West Developments makes no representations or warranties of any kind with respect to this website or the content contained on it, including any text, graphics, advertisements, links or other items. Furthermore, neither East West Developments nor any other contributor to this website make any representation or gives any warranty, condition, undertaking or term either expressed or implied as to the condition, quality, performance, accuracy, fitness for purpose, completeness or freedom from viruses of the content contained on this website or that such content will be accurate, up to date, uninterrupted or error free. Nothing on this website shall be regarded or taken as financial advice. 
Copyrights
This Web site and information contains copyrighted material, trademarks, and other proprietary information. You may not modify, publish, transmit, participate in the transfer or sale of, create derivative works of, or in any way exploit, in whole or in part, any Proprietary or other Material.   
License 
All images, text, contents, products and scripts are licensed and never sold, unless otherwise stated. Reproduction is prohibited. You may not use, copy, emulate, clone, rent, lease, sell, modify, recompile, disassemble, otherwise reverse engineer, or transfer the licensed program or product, or any subset of the licensed program or product, except as provided for in this agreement or expressly in writing. Any such unauthorized use shall result in immediate and automatic termination and breach and may result in criminal and/or civil prosecution.  
 PRIVACY POLICY  
eastwestdevelopments.com strives to offer its visitors the many advantages of Internet technology and to provide an interactive and personalized experience. We may use Personally Identifiable Information (your name, e-mail address, street address, telephone number) subject to the terms of this privacy policy. We will never sell, barter, or rent your email address to any unauthorized third party. Period."  
How we gather information from users 
How we collect and store information depends on the page you are visiting, the activities in which you elect to participate and the services provided. For example, you may be asked to provide information when you register for access to certain portions of our site or request certain features, such as newsletters or when you make a purchase. You may provide information when you participate in sweepstakes and contests, message boards and chat rooms, and other interactive areas of our site.  
Like most Web sites, eastwestdevelopments.com also collects information automatically and through the use of electronic tools that may be transparent to our visitors. For example, we may log the name of your Internet Service Provider or use cookie technology to recognize you and hold information from your visit. Among other things, the cookie may store your user name and password, sparing you from having to re-enter that information each time you visit, or may control the number of times you encounter a particular advertisement while visiting our site. As we adopt additional technology, we may also gather information through other means. In certain cases, you can choose not to provide us with information, for example by setting your browser to refuse to accept cookies, but if you do you may be unable to access certain portions of the site or may be asked to re-enter your user name and password, and we may not be able to customize the site's features according to your preferences.  
What we do with the information we collect 
Like other Web publishers, we collect information to enhance your visit and deliver more individualized content and advertising. We respect your privacy and do not share your information with anyone.  
Aggregated Information (information that does not personally identify you) may be used in many ways. For example, we may combine information about your usage patterns with similar information obtained from other users to help enhance our site and services (e.g., to learn which pages are visited most or what features are most attractive). Aggregated Information may occasionally be shared with our advertisers and business partners. Again, this information does not include any Personally Identifiable Information about you or allow anyone to identify you individually.  
We may use Personally Identifiable Information collected on eastwestdevelopments.com to communicate with you about your registration and customization preferences; our Terms of Service and privacy policy; services and products offered by eastwestdevelopments.com and other topics we think you might find of interest.  
Personally Identifiable Information collected by eastwestdevelopments.com may also be used for other purposes, including but not limited to site administration, troubleshooting, processing of e-commerce transactions, administration of sweepstakes and contests, and other communications with you. Certain third parties who provide technical support for the operation of our site (our Web hosting service for example) may access such information. We will use your information only as permitted by law. In addition, from time to time as we continue to develop our business, we may sell, buy, merge or partner with other companies or businesses. In such transactions, user information may be among the transferred assets. We may also disclose your information in response to a court order, at other times when we believe we are reasonably required to do so by law, in connection with the collection of amounts you may owe to us, and/or to law enforcement authorities whenever we deem it appropriate or necessary. Please note we may not provide you with notice prior to disclosure in such cases.  
Affiliated sites, linked sites and advertisements 
eastwestdevelopments.com expects its partners, advertisers and affiliates to respect the privacy of our users. Be aware, however, that third parties, including our partners, advertisers, affiliates and other content providers accessible through our site, may have their own privacy and data collection policies and practices. For example, during your visit to our site you may link to, or view as part of a frame on a eastwestdevelopments.com page, certain content that is actually created or hosted by a third party. Also, through eastwestdevelopments.com you may be introduced to, or be able to access, information, Web sites, features, contests or sweepstakes offered by other parties. eastwestdevelopments.com is not responsible for the actions or policies of such third parties. You should check the applicable privacy policies of those third parties when providing information on a feature or page operated by a third party.  
eastwestdevelopments.com expects its partners, advertisers and affiliates to respect the privacy of our users. Be aware, however, that third parties, including our partners, advertisers, affiliates and other content providers accessible through our site, may have their own privacy and data collection policies and practices. For example, during your visit to our site you may link to, or view as part of a frame on a eastwestdevelopments.com page, certain content that is actually created or hosted by a third party. Also, through eastwestdevelopments.com you may be introduced to, or be able to access, information, Web sites, features, contests or sweepstakes offered by other parties. eastwestdevelopments.com is not responsible for the actions or policies of such third parties. You should check the applicable privacy policies of those third parties when providing information on a feature or page operated by a third party.  
You should also be aware that if you voluntarily disclose Personally Identifiable Information on message boards or in chat areas, that information can be viewed publicly and can be collected and used by third parties without our knowledge and may result in unsolicited messages from other individuals or third parties. Such activities are beyond the control of eastwestdevelopments.com and this policy.  
Children 
eastwestdevelopments.com does not knowingly collect or solicit Personally Identifiable Information from or about children under 18 except as permitted by law. If we discover we have received any information from a child under 18 in violation of this policy, we will delete that information immediately. If you believe eastwestdevelopments.com has any information from or about anyone under 18, please contact us at the address listed below.  
Contacting Us 
We can be reached by contacting:
Email: info@eastwestdevelopments.com
Changes to this Policy
eastwestdevelopments.com reserves the right to change this policy at any time. Please check this page periodically for changes. Your continued use of our site following the posting of changes to these terms will mean you accept those changes. Information collected prior to the time any change is posted will be used according to the rules and laws that applied at the time the information was collected.   
Governing law 
This policy and the use of this Site are governed by the laws of India. If a dispute arises under this Policy we agree to first try to resolve it with the help of a mutually agreed-upon mediator in the following location: Delhi.  
If it proves impossible to arrive at a mutually satisfactory solution through mediation, we agree to submit the dispute to binding arbitration at the following location: Delhi. Judgment upon the award rendered by the arbitration may be entered in any court with jurisdiction to do so.  
www.eastwestdevelopments.com is controlled, operated and administered by webmasters from India This statement and the policies outlined herein are not intended to and do not create any contractual or other legal rights in or on behalf of any party.  
 

                        This website is  under construction                                        

All services to all the enquiries may not be available. It is our efforts to improve and perfect the website with full back up, customer support services and marketing support services. Investors are informed to check the website often to keep current with the latest contents on the website.

  Jaisalmer CondoHotel  |  Mozambique CondoHotel  |  Slovakia CondoHotel  |  Turkey CondoHotel  |  Nigeria CondoHotel  |  Zanzibar CondoHotel  |  S.Africa CondoHotel  |  Dellhi CondoHotel    |   Hospital Condos  |  Pune CondoHotel  |  Car Giveaway Draw  |  What are CondoHotels ?  |  Completed&running CondoHotels  |  Under Construction CondoHotels & developments  |  Disclaimer  |  DubaiCondo Resale's  |  100%Finance-monthly Payments  |  Flipping Properties  |  Forms etc  |  FAQ  |  India Key Facts  |  News  |  Links  |  Become Our Partner  |  Partnership Form  |  Terms & Conditions   |  Pre-construction  |  Pre-Launch  |  Property Exchange  |  Realtors Agents  |  More Info  |  Resale Pool  |  Why Invest in Property ?   |  Wiring Funds   |  FREE draw for a chance to win a Mercedez car by subscribing to our - FREE Hot Property Alert Newsletter

Use of this site is subject to East West Developments Terms of Use. Please review our Terms & Conditions. before doing business with us.
Copyright © eastwestdevelopments.com 2006. All rights reserved.
No portion of this page may be reproduced without our written permission. East West Developments are registered trademarks (TM) of eastwestdevelopments.com
   Registered in Gibraltar. ®

CLICK HERE TO SEND THIS PAGE TO A FRIEND!

Site is optimized for 800 x 600 pixels
Copyright © 2006. East West Developments